Terms & Conditions

01. Agreement to These Terms

These Terms & Conditions (“Terms”) govern your access to and use of the US Patriot Steel website, landing pages, quote forms, communications, and related online services. The terms “US Patriot Steel,” “Company,” “we,” “our,” and “us” refer to US Patriot Steel. The terms “you” and “your” refer to the person using the website or submitting information to us.

By using our website, submitting a quote request, calling us, checking an SMS consent box, or otherwise communicating with us, you agree to these Terms. If you do not agree, do not use the website or submit information through our forms.

02. Website Purpose

The website is provided for informational, marketing, and lead-generation purposes. It allows visitors to learn about steel building options, view project examples, request information, and submit quote requests.

The website does not create a binding purchase agreement, construction contract, engineering agreement, installation agreement, financing agreement, warranty agreement, or supplier agreement. Any actual purchase, project, delivery, installation, warranty, or service arrangement must be confirmed through separate written documentation.

03. Quote Requests

When you submit a quote request, you agree to provide accurate, current, and complete information. This may include your name, email, phone number, state, ZIP code, building type, building size, estimated erection date, and project details.

A quote request is not a final price, final design, final engineering determination, or guaranteed availability. Any pricing, specifications, drawings, delivery dates, project timelines, product availability, warranty terms, or service terms are subject to review and written confirmation.

US Patriot Steel may contact you to discuss your project and may request additional information before providing pricing or recommendations.

04. No Guarantee of Final Pricing or Availability

Information on the website is provided for general informational purposes. Prices, product availability, materials, design options, delivery timelines, engineering requirements, and other project details may change.

Any pricing shown, discussed, estimated, or provided is not final unless confirmed in a written agreement authorized by US Patriot Steel.

Final pricing may depend on many factors, including but not limited to:

• Building size
• Building type
• Project location
• Engineering requirements
• Local code requirements
• Wind, snow, seismic, or other load requirements
• Doors, windows, insulation, colors, and accessories
• Material costs
• Delivery requirements
• Site conditions
• Taxes, permits, fees, and other applicable charges
• Customer-requested changes
• Manufacturer, supplier, or installer availability

US Patriot Steel reserves the right to correct errors, update information, revise estimates, or decline a project where necessary.

05. Customer Responsibilities

You are responsible for reviewing your project requirements before making any purchase or project decision. Depending on the project, you may be responsible for:

• Confirming property boundaries and site conditions
• Confirming access for delivery, unloading, and installation
• Obtaining permits and approvals
• Complying with zoning requirements
• Confirming local building codes
• Reviewing HOA, municipal, county, or state restrictions
• Preparing the site
• Ensuring the site is level, accessible, and ready where applicable
• Hiring qualified contractors where needed
• Confirming foundation requirements
• Reviewing final drawings, specifications, and documentation
• Paying applicable taxes, permit fees, inspection fees, and other project costs

US Patriot Steel is not responsible for delays, costs, penalties, cancellations, or issues caused by inaccurate customer information, site restrictions, permit problems, local code requirements, lack of site readiness, or customer failure to review project details.

06. Building Codes, Permits, and Local Requirements

Building requirements vary by state, county, municipality, property type, and intended use. You are responsible for confirming applicable codes, zoning rules, permits, inspections, setbacks, HOA requirements, and other local requirements before proceeding with a project.

US Patriot Steel may provide general guidance, but local requirements must be verified with the appropriate local authorities, building departments, engineers, contractors, or other qualified professionals.

07. Website Information and Product Descriptions

We make reasonable efforts to provide accurate and useful information. However, website content may contain errors, outdated information, omissions, or generalizations.

All website content is provided “as is” and for informational purposes only. We do not warrant that website content is complete, accurate, current, error-free, or suitable for your specific project.

You should speak with a company representative and, where appropriate, qualified local professionals before making project decisions.

08. Building Images, Renderings, Colors, and Examples

Images, galleries, renderings, project examples, illustrations, color samples, and photos shown on the website are for general reference and illustrative purposes only.

Actual buildings, colors, dimensions, materials, doors, windows, layouts, finishes, accessories, and designs may vary. Displayed colors may also vary based on screen settings, lighting, photo editing, manufacturing changes, and supplier availability.

A displayed image does not guarantee that the exact same building, price, option, color, configuration, warranty, or feature is available for your project.

09. Engineering, Drawings, and Specifications

Any design, engineering, drawing, or specification information must be confirmed in final written documentation. Preliminary discussions, website content, quote forms, photo examples, renderings, or general recommendations should not be treated as final engineering advice.

You are responsible for reviewing final drawings, specifications, engineering documents, and project details before approval or purchase.

10. Orders, Deposits, Payments, and Cancellations

If a project requires a deposit, payment, order confirmation, signed agreement, or written approval, those terms will be governed by the applicable written agreement, invoice, order form, proposal, or contract provided by US Patriot Steel.

Deposits, payment schedules, refund rules, cancellation terms, change-order terms, and order modifications may vary depending on the project and must be confirmed in writing.

Do not rely on general website content as a substitute for written order terms.

If a deposit is used to begin processing, design, pricing lock, production, engineering, scheduling, vendor coordination, or order fulfillment, the applicable deposit rules should be reviewed before payment.

11. Delivery, Installation, and Timelines

Any delivery date, installation date, erection date, production date, or project timeline is an estimate unless expressly confirmed in writing.

Timelines may be affected by:

• Material availability
• Engineering requirements
• Weather
• Transportation delays
• Site readiness
• Permit or inspection delays
• Customer approvals
• Change orders
• Supplier, manufacturer, or installer availability
• Labor conditions
• Road conditions or access limitations
• Events outside our reasonable control

US Patriot Steel is not responsible for delays caused by factors beyond its reasonable control or by customer failure to provide accurate information, approvals, access, or site readiness.

12. Change Orders and Project Modifications

Any requested change to building size, design, specifications, accessories, delivery, installation, or other project details may affect pricing, timeline, availability, engineering requirements, and final documentation.

No change is binding unless reviewed and approved in writing by US Patriot Steel or the applicable authorized party.

13. Warranties

Any warranties applicable to a building, materials, workmanship, installation, paint, panels, framing, or components are governed only by the written warranty terms provided for the specific project.

Website statements, photos, examples, marketing copy, or general descriptions do not create additional warranties.

To the fullest extent permitted by law, US Patriot Steel disclaims all warranties not expressly stated in final written documentation, including implied warranties of merchantability, fitness for a particular purpose, and non-infringement.

14. SMS Marketing and Text Message Terms

By providing your phone number and checking the SMS consent box on our website, you agree to receive SMS text messages from US Patriot Steel regarding your inquiry, estimate request, services, appointment updates, and related follow-up communications.

Message and data rates may apply. Message frequency may vary. Consent is not a condition of purchase.

You may opt out of SMS messages at any time by replying STOP. You may reply HELP for assistance.

By opting in, you confirm that:

• You are the account holder or authorized user of the phone number provided.
• You are at least 18 years old or have the legal authority to provide consent.
• You consent to receive text messages related to your inquiry, quote request, appointments, service updates, and related follow-up communications.
• You understand that your mobile carrier may charge message and data rates.
• You understand that message frequency may vary.
• You understand that replying STOP will opt you out of future SMS messages, except where further communication is permitted by law.
• You understand that SMS delivery may depend on carrier networks and is not guaranteed.

US Patriot Steel is not responsible for delayed or undelivered text messages caused by mobile carriers, network issues, device settings, or other factors outside our control.

15. Email and Phone Communications

By submitting your contact information, you authorize US Patriot Steel to contact you by phone, email, SMS/text message, or other permitted methods regarding your inquiry, quote request, project, services, and related communications.

You may opt out of marketing emails by using any available unsubscribe link or by contacting us directly. You may opt out of SMS messages by replying STOP.

Phone calls may be recorded or monitored for quality assurance, training, recordkeeping, or business purposes where permitted by law.

16. User Conduct

You agree not to use the website for any unlawful, abusive, fraudulent, misleading, or harmful purpose. You agree not to:

• Submit false or misleading information
• Attempt to interfere with website operation
• Attempt to gain unauthorized access to systems
• Use automated tools to scrape, spam, or misuse website content
• Transmit malware, spam, or harmful code
• Violate applicable laws or regulations
• Impersonate another person or entity
• Use the website to infringe any third-party rights

We reserve the right to restrict or terminate access to the website if we believe these Terms have been violated.

17. Intellectual Property

The website and its content, including text, graphics, images, logos, design elements, icons, layouts, photos, galleries, and other materials, are owned by or licensed to US Patriot Steel and are protected by applicable intellectual property laws.

You may view the website for personal or business informational purposes. You may not copy, reproduce, modify, distribute, sell, resell, publish, license, create derivative works from, or exploit website content without written permission.

18. Third-Party Services and Links

The website may include links, embedded tools, maps, videos, review widgets, analytics scripts, advertising platforms, call tracking systems, or other third-party services.

We are not responsible for third-party websites, services, content, policies, terms, or practices. Your use of third-party services may be governed by their own terms and privacy policies.

19. Disclaimer of Warranties

The website and its content are provided on an “as is” and “as available” basis. To the fullest extent permitted by law, US Patriot Steel disclaims all warranties, express or implied, including warranties of accuracy, completeness, merchantability, fitness for a particular purpose, non-infringement, website availability, and error-free operation.

We do not warrant that the website will be uninterrupted, secure, error-free, updated, or free from viruses or harmful components.

20. Limitation of Liability

To the fullest extent permitted by law, US Patriot Steel and its owners, employees, agents, contractors, vendors, service providers, suppliers, and affiliates will not be liable for any indirect, incidental, special, consequential, punitive, exemplary, or similar damages arising out of or related to your use of the website, reliance on website content, submission of information, communications with us, quote requests, third-party services, or inability to use the website.

This limitation applies even if we have been advised of the possibility of such damages and regardless of the legal theory, including contract, tort, negligence, strict liability, or otherwise.

Some jurisdictions do not allow certain limitations, so some of the above limitations may not apply to you.

21. Indemnification

You agree to indemnify, defend, and hold harmless US Patriot Steel, its owners, employees, agents, contractors, vendors, service providers, suppliers, and affiliates from and against any claims, damages, liabilities, losses, costs, or expenses, including reasonable attorneys’ fees, arising out of or related to:

• Your use of the website
• Your submission of inaccurate or misleading information
• Your violation of these Terms
• Your violation of any law or regulation
• Your infringement of any third-party rights
• Your project decisions based on incomplete or unverified information
• Site conditions, permit issues, access issues, or local code requirements related to your project

22. No Professional Advice

Website content is provided for general informational purposes only. It should not be considered legal, engineering, architectural, construction, zoning, permitting, tax, financing, insurance, or professional advice.

You should consult qualified professionals before making decisions involving building codes, permits, engineering requirements, site preparation, financing, construction, insurance, or legal obligations.

23. Force Majeure

US Patriot Steel will not be responsible for delays or failure to perform caused by events beyond its reasonable control, including but not limited to severe weather, natural disasters, labor disruptions, supply chain interruptions, transportation delays, material shortages, supplier or manufacturer issues, government actions, permit delays, power outages, internet disruptions, emergencies, or other events outside our control.

24. Disputes and Governing Law

These Terms will be governed by the laws of the state in which US Patriot Steel operates, without regard to conflict of law principles, unless otherwise required by applicable law or a separate written agreement.

If a specific governing law, venue, arbitration clause, or dispute resolution process should apply, the appropriate language will be inserted after attorney review.

25. Severability

If any part of these Terms is found to be invalid, unlawful, or unenforceable, that provision will be limited or removed to the minimum extent necessary, and the remaining provisions will remain in full force and effect.

26. No Waiver

Our failure to exercise or enforce any right or provision of these Terms does not constitute a waiver of that right or provision.

27. Assignment

You may not assign your rights or obligations under these Terms without our prior written consent. US Patriot Steel may assign or transfer these Terms, in whole or in part, in connection with business operations, service providers, restructuring, sale, merger, or transfer of assets, where permitted by law.

28. Entire Agreement

These Terms, together with the Privacy Policy and any applicable written agreement, order form, invoice, proposal, or project documentation, represent the entire agreement between you and US Patriot Steel regarding website use and related online interactions.

In the event of a conflict between website Terms and a signed written agreement for a specific project, the signed written agreement will control for that project.

29. Changes to These Terms

We may update these Terms from time to time. When we update them, we will revise the “Last Updated” date at the top of the page.

Your continued use of the website after changes are posted means you accept the updated Terms.

30. Contact Information

If you have questions about these Terms & Conditions, please contact us: